E51 Automation (Kongshaugen sewage treatment plant)

The builder shall enter into a contract with one contractor for the execution of contract E51 Automation. Ålesund municipality is the contract party. The builder shall enter into a contract with one contractor for the execution of contract E51 Automation. Ålesund municipality is the contract party.

CPV: 45000000 Roboty budowlane, 32420000 Urządzenia sieciowe, 45232430 Roboty w zakresie uzdatniania wody, 45252000 Roboty budowlane w zakresie budowy zakładów uzdatniania, oczyszczania oraz spalania odpadów, 45252200 Wyposażenie oczyszczalni ścieków, 45252210 Roboty budowlane w zakresie zakładów oczyszczania wody, 48900000 Różne pakiety oprogramowania i systemy komputerowe, 48921000 System automatyzacji, 72000000 Usługi informatyczne: konsultacyjne, opracowywania oprogramowania, internetowe i wsparcia, 72200000 Usługi doradcze w zakresie programowania oprogramowania, 72243000 Usługi programowania
Miejsce wykonania:
E51 Automation (Kongshaugen sewage treatment plant)
Miejsce udzielenia zamówienia:
Ålesund kommune
Numer nagrody:
87161

1. Buyer

1.1 Buyer

Official name : Ålesund kommune
Activity of the contracting entity : Water-related activities

2. Procedure

2.1 Procedure

Title : E51 Automation (Kongshaugen sewage treatment plant)
Description : The builder shall enter into a contract with one contractor for the execution of contract E51 Automation. Ålesund municipality is the contract party.
Procedure identifier : 18c7917f-1a7e-469c-adee-f97f71cff297
Previous notice : 9053c03a-7d18-4bb8-8270-d8756d06e81e-01
Internal identifier : 87161
Type of procedure : Negotiated with prior publication of a call for competition / competitive with negotiation
The procedure is accelerated : no
Main features of the procedure : Ålesund municipality and Sula municipality cooperate through the project "BLÅ – fjords for the future", to construct a new sewage treatment plant at Kongshaugen (Kvasnes) in Sula municipality. The aims in the project are as follows: Cleaner fjord systemLovlig system for sewage waterBærekraftig system for the futureIt new sewage treatment facility shall have sufficient treatment capacity to handle sewage water that shall be supplied from Sula municipality and Ålesund municipality, and shall be designed as a secondary treatment facility. The treatment facility shall be constructed in rock. The contract includes the following: Rock installations and administration buildings: Automation equipment such as PLS, IO, network equipment etc. for assembly in the automation boards described in the contract E41 Electro technical installations, the rock plant Kongshaugen. Software and programming, testing and commissioning of PLC equipment for control and interface with a top system delivered by Ålesund municipality. Automation equipment such as PLS, IO, network equipment etc. for assembly in the boards described in the contract E21 Construction work Kongshaugen. Software and programming, testing and commissioning of PLC equipment for control and interface with the top system delivered by Ålesund municipality for approx. 13 pump stations, valve houses/valve manholes etc. on the transfer system. See the tender documentation part II for further information on the contents of the procurement. See part II - E. The abidance deadline: 3 months after the final tender has been submitted for information.

2.1.1 Purpose

Main nature of the contract : Works
Main classification ( cpv ): 45000000 Construction work
Additional classification ( cpv ): 32420000 Network equipment
Additional classification ( cpv ): 45232430 Water-treatment work
Additional classification ( cpv ): 45252000 Construction works for sewage treatment plants, purification plants and refuse incineration plants
Additional classification ( cpv ): 45252200 Purification plant equipment
Additional classification ( cpv ): 45252210 Water purification plant construction work
Additional classification ( cpv ): 48900000 Miscellaneous software package and computer systems
Additional classification ( cpv ): 48921000 Automation system
Additional classification ( cpv ): 72000000 IT services: consulting, software development, Internet and support
Additional classification ( cpv ): 72200000 Software programming and consultancy services
Additional classification ( cpv ): 72243000 Programming services

2.1.2 Place of performance

Country subdivision (NUTS) : Møre og Romsdal ( NO0A3 )
Country : Norway

2.1.4 General information

Call for competition is terminated
Legal basis :
Directive 2014/25/EU
Forsyningsforskriften - The supply regulations §§ 9-1, cf. § 19-7.

5. Lot

5.1 Lot technical ID : LOT-0000

Title : E51 Automation (Kongshaugen sewage treatment plant)
Description : The builder shall enter into a contract with one contractor for the execution of contract E51 Automation. Ålesund municipality is the contract party.
Internal identifier : 87161

5.1.1 Purpose

Main nature of the contract : Works
Main classification ( cpv ): 45000000 Construction work
Additional classification ( cpv ): 32420000 Network equipment
Additional classification ( cpv ): 45232430 Water-treatment work
Additional classification ( cpv ): 45252000 Construction works for sewage treatment plants, purification plants and refuse incineration plants
Additional classification ( cpv ): 45252200 Purification plant equipment
Additional classification ( cpv ): 45252210 Water purification plant construction work
Additional classification ( cpv ): 48900000 Miscellaneous software package and computer systems
Additional classification ( cpv ): 48921000 Automation system
Additional classification ( cpv ): 72000000 IT services: consulting, software development, Internet and support
Additional classification ( cpv ): 72200000 Software programming and consultancy services
Additional classification ( cpv ): 72243000 Programming services

5.1.2 Place of performance

Country subdivision (NUTS) : Møre og Romsdal ( NO0A3 )
Country : Norway
Additional information :

5.1.6 General information

Procurement Project not financed with EU Funds.
The procurement is covered by the Government Procurement Agreement (GPA) : yes

5.1.7 Strategic procurement

5.1.10 Award criteria

Criterion :
Type : Price
Name : Price
Description : The price will be assessed on the basis of the total sum stated in the summary of price-bearing items in the quantity description.
Criterion :
Type : Quality
Name : Implementation of the assignments
Description : The contracting authority will evaluate the following under the award criteria "Assignment Implementation": 1. To what degree the contractor has a good, concrete and project adapted plan for the project as regards: > Testing and Commissioning > Co-ordination with other contracts for the treatment plant and transfer facility. > How the contractor will work to avoid delays in deliveries that affect the progress of the project. 2. The contractor ́s progress plan with milestones and completion dates. Emphasis will also be put on whether the plan is realistic, robust and thoughtful.
Criterion :
Type : Quality
Name : Project organisation
Description : The contracting authority will evaluate the following under the award criteria "Project Organisation": 1. Whether the contractor has an organisation that is adapted to the project, with clear roles and areas of responsibility. 2. The offered key personnel ́ relevant formal competence and experience from previous assignments. Key personnel means project manager and two central project employees.

5.1.15 Techniques

Framework agreement :
No framework agreement
Information about the dynamic purchasing system :
No dynamic purchase system

5.1.16 Further information, mediation and review

Review organisation : Møre og Romsdal tingrett
Information about review deadlines : The contract award was held 30.06.2025 and the waiting period expired 10.07.2025. The contract was signed 11.07.2025.
Organisation providing information concerning the general regulatory framework for taxes applicable in the place where the contract is to be performed : Møre og Romsdal tingrett
Organisation providing information concerning the general regulatory framework for environmental protection applicable in the place where the contract is to be performed : Møre og Romsdal tingrett
Organisation providing information concerning the general regulatory framework for employment protection and working conditions applicable in the place where the contract is to be performed : Møre og Romsdal tingrett
Organisation providing additional information about the procurement procedure : Inventura AS
Organisation whose budget is used to pay for the contract : Ålesund kommune
Organisation signing the contract : Ålesund kommune

6. Results

Value of all contracts awarded in this notice : 5 872 143 Norwegian krone

6.1 Result lot ldentifier : LOT-0000

At least one winner was chosen.

6.1.2 Information about winners

Winner :
Official name : Tratec Norcon AS
Tender :
Tender identifier : Tilbud E51 - Tratec Norcon AS
Identifier of lot or group of lots : LOT-0000
Value of the tender : 5 872 143 Norwegian krone
The tender is a variant : no
Subcontracting : No
Contract information :
Identifier of the contract : Kontrakt - E51 Automasjon
Date on which the winner was chosen : 30/06/2025
Date of the conclusion of the contract : 11/07/2025
Organisation signing the contract : Ålesund kommune

6.1.3 Non-winning tenderers :

Tenderer :
Official name : Caverion Norge AS
Tenderer :
Official name : Nordkontakt AS

6.1.4 Statistical information

Summary of the review requests the buyer received :
Number of complainants : 0
Received tenders or requests to participate :
Type of received submissions : Requests to participate
Number of tenders or requests to participate received : 7
Type of received submissions : Tenders
Number of tenders or requests to participate received : 3

8. Organisations

8.1 ORG-0001

Official name : Inventura AS
Registration number : 983351417
Postal address : Solheimsgaten 15
Town : Bergen
Postcode : 5058
Country subdivision (NUTS) : Vestland ( NO0A2 )
Country : Norway
Contact point : Saffa Galal
Telephone : +47 55134480
Internet address : https://www.inventura.no
Roles of this organisation :
Organisation providing additional information about the procurement procedure

8.1 ORG-0002

Official name : Ålesund kommune
Registration number : 929911709
Postal address : Keiser Wilhelms gate 11
Town : Ålesund
Postcode : 6003
Country subdivision (NUTS) : Møre og Romsdal ( NO0A3 )
Country : Norway
Contact point : Saffa Galal
Telephone : +47 41598766
Roles of this organisation :
Buyer
Organisation signing the contract
Organisation whose budget is used to pay for the contract

8.1 ORG-0003

Official name : Møre og Romsdal tingrett
Registration number : 926723200
Postal address : Postboks 1354 Sentrum
Town : Ålesund
Postcode : 6001
Country subdivision (NUTS) : Møre og Romsdal ( NO0A3 )
Country : Norway
Telephone : +47 70334700
Roles of this organisation :
Review organisation
Organisation providing information concerning the general regulatory framework for taxes applicable in the place where the contract is to be performed
Organisation providing information concerning the general regulatory framework for environmental protection applicable in the place where the contract is to be performed
Organisation providing information concerning the general regulatory framework for employment protection and working conditions applicable in the place where the contract is to be performed

8.1 ORG-0004

Official name : Tratec Norcon AS
Size of the economic operator : Medium
Registration number : 930798290
Postal address : Vigeland Brugs veg 21
Town : VENNESLA
Postcode : 4708
Country subdivision (NUTS) : Agder ( NO092 )
Country : Norway
Contact point : Tratec Norcon AS
Telephone : 38152600
Fax : 38152601
Roles of this organisation :
Tenderer
Winner of these lots : LOT-0000

8.1 ORG-0005

Official name : Caverion Norge AS
Size of the economic operator : Large
Registration number : 959069743
Postal address : Brobekkveien 80
Town : Oslo
Postcode : 0582
Country subdivision (NUTS) : Oslo ( NO081 )
Country : Norway
Roles of this organisation :
Tenderer

8.1 ORG-0006

Official name : Nordkontakt AS
Size of the economic operator : Medium
Registration number : 946951323
Postal address : Jernbaneveien 23
Town : Bodø
Postcode : 8012
Country subdivision (NUTS) : Nordland/Nordlánnda ( NO071 )
Country : Norway
Roles of this organisation :
Tenderer

Notice information

Notice identifier/version : 1a78d441-7d13-4600-87d8-4dcedfafdf18 - 01
Form type : Result
Notice type : Contract or concession award notice – standard regime
Notice dispatch date : 04/08/2025 08:39 +00:00
Notice dispatch date (eSender) : 04/08/2025 10:58 +00:00
Languages in which this notice is officially available : English
Notice publication number : 00512536-2025
OJ S issue number : 148/2025
Publication date : 05/08/2025