1.1 Buyer
Official name
:
European Union Agency for the Space Programme
G2G IOV Ground Control Segment
Als Teil des gesamten Bodensegments der 2. Generation der Galileo In-Orbit-Validierung (G2G IOV Ground Segment), besteht der Hauptzweck des G2G IOV- Ground Control Segment in der Bereitstellung der relevanten Bodenkontrollsystemfähigkeiten. Osana Galileon toisen sukupolven kiertoradalla validoinnin maasegmenttiä (G2G IOV:n maasegmentti) G2G IOV:n maanpäällisen ohjaustekniikan segmentin päätavoite on toimittaa asianmukaisia maanpäällisiä …
CPV: 32500000 Telekomunikacijska oprema i potrepštine
1. Buyer
1.1 Buyer
Official name
:
European Commission, Directorate-General for Defence Industry and Space (DEFIS), DEFIS.C.2 – Satellite Navigation
2. Procedure
2.1 Procedure
Title
:
G2G IOV Ground Control Segment
Description
:
As part of the overall Galileo 2nd Generation In-Orbit Validation Ground Segment (G2G IOV Ground Segment), the G2G IOV Ground Control Segment has as main purpose the delivery of the relevant Ground Control System capabilities.
Procedure identifier
:
c82f9293-db15-45fd-ada0-bbba09e586a2
2.1.1 Purpose
Main classification
(
cpv
):
32500000
Telecommunications equipment and supplies
2.1.4 General information
Additional information
:
The value of the contract disclosed in Section V.2.4) is the baseline value of the contract (EUR 147 850 000) plus the value of options M and N. These two options were activated at contract signature while the other options disclosed in Section II.2.11) were not.
Legal basis
:
Regulation (EU, Euratom) 2018/1046
5. Lot
5.1 Lot technical ID : LOT-0000
Title
:
G2G IOV Ground Control Segment
Description
:
As part of the overall Galileo 2nd Generation In-Orbit Validation Ground Segment (G2G IOV Ground Segment), the G2G IOV Ground Control Segment has as main purpose the delivery of the relevant Ground Control System capabilities as an upgrade of the Galileo infrastructure in order to contribute to the following two versions of the system: 1. a first version supporting the LEOP, IOT and operations of up to two new families of Galileo Second Generation Batch #1 (G2SB1) satellites, with the first launch planned in November 2024; and 2. a second version of the system for the provision of legacy services, early versions of G2 system capabilities and overall G2G In-Orbit Validation activities. Options in this procurement will include among other additional TTC station deployment, maintenance activities.
5.1.1 Purpose
Main classification
(
cpv
):
32500000
Telecommunications equipment and supplies
Options
:
Description of the options
:
Option A – Release 4.1 – deployment on OPE chains and remote sites (EUR 3 995 939). Option B – L2/L3 Maintenance extension of release 4.0 (2 x EUR 2 978 298). This option can be exercised twice. Option C – L2/L3 Maintenance extension of release 4.1 (EUR 7 914 672). Option D – Hand-over of 4.0 L2/L3 maintenance to a third party (EUR 316 981) – prerequisite: activation of opt. B. Option E – Hand-over of 4.1 L2/L3 maintenance to a third party (EUR 341 825) – prerequisite: activation of opt. C. Option F – L2/L3 environment handover (EUR 146 187) – prerequisite activation of option B. Option G – L2/L3 environment handover (EUR 147 158) – prerequisite activation of option C. Option H1 – On-call maintenance support (2 x EUR 181 269). This option can be exercised twice and option B activation 1s a prerequisite. Option H2 – On-call maintenance support (EUR 369 424) – prerequisite activation of option C. Option I1 – Release 4.0 Warranty (EUR 1 359 011). Option I2 – Release 4.1 Warranty (EUR 2 082 418). Option J – GCS additional TTCF development and deployment (EUR 9 905 876). Option K – Additional deployment of TTC sharing capability (EUR 417 232 x 6). This option can be exercised up to six times. Option L – 4.1 Deployment on additional TTCF (3 x EUR 691 765). This option can be exercised up to three times. Option M – G1 mode HSM early deployment (EUR 3 160 588). Option N – Customer undertakings delay risk mitigation (EUR 4 448 917). Option O – Customer undertakings earlier provision (EUR 670 438).
5.1.6 General information
Procurement Project fully or partially financed with EU Funds.
The procurement is covered by the Government Procurement Agreement (GPA)
:
no
Additional information
:
Option M and N were activated at contract signature.
5.1.16 Further information, mediation and review
Review organisation
:
General Court of European Union
-
Information about review deadlines
:
Within 2 months of the notification to the plaintiff, or, in absence thereof, of the day on which it came to the knowledge of the plaintiff. A complaint to the European Ombudsman does not have as an effect either to suspend this period or to open a new period for lodging appeals.
Organisation providing more information on the review procedures
:
General Court of European Union
-
6. Results
Value of all contracts awarded in this notice
:
205 328 567
Euro
6.1 Result lot ldentifier : LOT-0000
6.1.2 Information about winners
Winner
:
Official name
:
GMV Aerospace and Defence S.A.U.
Tender
:
Tender identifier
:
TEN-0001
Identifier of lot or group of lots
:
LOT-0000
Value of the tender
:
243 476 317
Euro
Subcontracting
:
Yes
Subcontracting value is known
:
no
Subcontracting percentage is known
:
no
Contract information
:
Identifier of the contract
:
4000141593/23/NL/CS
Title
:
Galileo 2nd Generation (G2G) In-Orbit Validation (IOV) Ground Control Segment (GCS)
Date of the conclusion of the contract
:
14/06/2023
7. Modification
7.1 Modification
Identifier of the previous contract award notice
:
521882-2023
Identifier of the modified contract
:
CON-0001
Reason for modification
:
Need for additional works, services or supplies by the original contractor.
Description
:
CCN1: The change is motivated by the need to implement in the technical baseline the consequences of the G2 crypto documentation already applicable in the contract CISL 1.3 as foreseen in the SOW "G2 Crypto Flexibility Clause". CCN3: The change is motivated by the need to re-baseline the schedule due to changes to key milestones and delivery dates from G2SA and G2SB due to crypto compliance recovery requested and the new launchers services availability schedule.
7.1.1 Change
Description of modifications
:
Modification CCN1: Formalises the conclusions from the co-engineering between ESA, GMV, and its subcontractors (i.e., HSM and KMF providers) on the DCN G2G-DCN-ESA-SYST-X-50013-x (updated as part of G2 crypto flexibility clause) being officially flow-down through the CISL 1.3 ([AD.2]) that, in addition to making applicable other documents. Some of them also covered by the G2 crypto flexibility clause, and other introducing new requirements which compliance cover either by baseline (i.e. Task#1 and Task#2) or by options that enhance the baseline compliance (i.e. Option#C). Modification CCN3: GCS needs to re-baseline the schedule due to changes to key milestones and delivery dates from G2SA and G2SB due to crypto compliance recovery requested and the new launchers services availability schedule. The total value of the contract indicated in the contract award notice (521882-2023) was 155,461,433.00 EUR (Total value of the procurement: 193,609,183.00 EUR). The total value of the contract consists of the baseline activities (147,851,928.00 EUR), including options M (3,160,588.00 EUR) and N (4,448,917.00 EUR). The options disclosed in Section II.2.11 of the contract award notice were included in the calculation of the “total value of the procurement”. Therefore, the “total value of the procurement” of the contract award notice was 193,609,183.00 EUR. Description of modifications: Modifications CCN1 and CCN3: Value increased by 5,648,109.00 EUR (CCN1) and 44,219,025.00 EUR (CCN3) (Total value of CCN1 and CCN3 including all options= 49,867,134.00 EUR). The “total contract value” is now updated to 205,328,567.00 EUR (while the “total value of the tender”, which includes also the options under Section II.2.11, is 243,476,317.00 EUR). Please note that both the European Commission and EUSPA are qualified as "buyer", as until 15 June 2023 the European Commission was the contracting authority, while as from the mentioned date EUSPA became the new contracting authority.
Business entity identifier in the previous notice
:
ORG-0002
8. Organisations
8.1 ORG-0001
Official name
:
European Commission, Directorate-General for Defence Industry and Space (DEFIS), DEFIS.C.2 – Satellite Navigation
Registration number
:
EC
Postal address
:
Avenue d'Auderghem 45
Town
:
Brussels
Postcode
:
1049
Country subdivision (NUTS)
:
Arr. de Bruxelles-Capitale/Arr. Brussel-Hoofdstad
(
BE100
)
Country
:
Belgium
Telephone
:
+32 2 299 11 11
Roles of this organisation
:
Buyer
8.1 ORG-0002
Official name
:
GMV Aerospace and Defence S.A.U.
Registration number
:
ESA79197356
Town
:
Tres Cantos
Postcode
:
28760
Country subdivision (NUTS)
:
Madrid
(
ES300
)
Country
:
Spain
Roles of this organisation
:
Tenderer
Winner of these lots
:
LOT-0000
8.1 ORG-0003
Official name
:
General Court of European Union
Registration number
:
GCEU
Postal address
:
Rue du Fort Niedergrünewald
Town
:
Luxembourg
Postcode
:
L-2925
Country subdivision (NUTS)
:
Luxembourg
(
LU000
)
Country
:
Luxembourg
Telephone
:
+352 4303-1
Fax
:
+352 4303-2100
Roles of this organisation
:
Review organisation
Organisation providing more information on the review procedures
8.1 ORG-0004
Official name
:
European Union Agency for the Space Programme
Registration number
:
EUSPA
Town
:
Prague
Postcode
:
17000
Country subdivision (NUTS)
:
Hlavní město Praha
(
CZ010
)
Country
:
Czechia
Telephone
:
+420 234 766 000
Roles of this organisation
:
Buyer
8.1 ORG-0000
Official name
:
Publications Office of the European Union
Registration number
:
PUBL
Town
:
Luxembourg
Postcode
:
2417
Country subdivision (NUTS)
:
Luxembourg
(
LU000
)
Country
:
Luxembourg
Telephone
:
+352 29291
Roles of this organisation
:
TED eSender
Notice information
Notice identifier/version
:
b8e51dec-da10-4572-9720-5f455191b875
-
01
Form type
:
Contract modification
Notice type
:
Contract modification notice
Notice dispatch date
:
24/03/2025
14:32 +00:00
Languages in which this notice is officially available
:
English
Danish, German, Spanish, Finnish, French, Greek, Italian, Dutch, Portuguese, Swedish, Czech, Estonian, Hungarian, Lithuanian, Latvian, Maltese, Polish, Slovak, Slovenian, Irish, Bulgarian, Romanian, Croatian
Notice publication number
:
00193649-2025
OJ S issue number
:
60/2025
Publication date
:
26/03/2025