Multi-Party Framework Agreement for Minor Works on foot of an initial contract for remedial works to various unoccupied buildings across the Digital Hub Development Agency campus

The Digital Hub Development Agency (DHDA), the Contracting Authority, is seeking to establish a Multi-Party Framework Agreement for Minor Works for suitably qualified and experienced Building Contractors on foot of an initial contract for remedial works to various unoccupied buildings across the Digital Hub Development Agency campus. The works that …

CPV: 45000000 Stavební práce, 45100000 Práce spojené s přípravou staveniště, 45110000 Demolice a zemní práce, 45200000 Práce pro kompletní nebo částečnou výstavbu inženýrské stavitelství, 45210000 Bytová výstavba, 45220000 Konstrukční a stavební práce, 45260000 Střešní práce a jiné specializované stavební práce, 45300000 Stavební montážní práce, 45310000 Elektroinstalační práce, 45320000 Izolační práce, 45330000 Instalatérské a sanitární práce, 45340000 Instalace a montáž oplocení, zábradlí a bezpečnostních zařízení, 45350000 Mechanická zařízení, 45400000 Práce při dokončování budov, 45410000 Omítací práce, 45420000 Stavební zámečnictví a stavební truhlářské práce, 45430000 Pokládání podlahových krytin a obkládání stěn, 45440000 Sklenářské, malířské a natěračské práce, 45450000 Ostatní dokončovací stavební činnosti
Místo provedení:
Multi-Party Framework Agreement for Minor Works on foot of an initial contract for remedial works to various unoccupied buildings across the Digital Hub Development Agency campus
Misto zadání:
The Digital Hub Development Agency
Číslo zakázky:
0

1. Buyer

1.1 Buyer

Official name : The Digital Hub Development Agency
Legal type of the buyer : Body governed by public law
Activity of the contracting authority : General public services

2. Procedure

2.1 Procedure

Title : Multi-Party Framework Agreement for Minor Works on foot of an initial contract for remedial works to various unoccupied buildings across the Digital Hub Development Agency campus
Description : The Digital Hub Development Agency (DHDA), the Contracting Authority, is seeking to establish a Multi-Party Framework Agreement for Minor Works for suitably qualified and experienced Building Contractors on foot of an initial contract for remedial works to various unoccupied buildings across the Digital Hub Development Agency campus. The works that are subject to the competition will involve interaction with protected and listed structures, with all proposed works requiring adherence to preservation best practices. A summary of the works is listed below, please note this a non-exhaustive list: - Installation of external supporting steelworks and remediation of existing supporting steelworks, including installation of internal propping elements. - Timber works include stair restoration/construction, timber floor strengthening and replacement, roof repairs. - Roof repair works including, restoration and new construction. - External facade works include render crack repair, brickwork pointing and cladding installation. - Underpinning to existing historic foundation. There are various other projects which are envisaged under the Framework Agreement, please refer to enclosed documents for further particulars and general description of the works. Note that works are predominantly carried out to unoccupied buildings but there will be a certain amount of works which will take place in occupied buildings.
Procedure identifier : 41fe8a1c-160c-487a-92ff-48abb527a30b
Previous notice : c8d3d0cc-d3a2-4cae-a70e-95055b8a2f65-01
Type of procedure : Negotiated with prior publication of a call for competition / competitive with negotiation
The procedure is accelerated : no

2.1.1 Purpose

Main nature of the contract : Works
Main classification ( cpv ): 45000000 Construction work
Additional classification ( cpv ): 45330000 Plumbing and sanitary works
Additional classification ( cpv ): 45340000 Fencing, railing and safety equipment installation work
Additional classification ( cpv ): 45350000 Mechanical installations
Additional classification ( cpv ): 45400000 Building completion work
Additional classification ( cpv ): 45410000 Plastering work
Additional classification ( cpv ): 45420000 Joinery and carpentry installation work
Additional classification ( cpv ): 45430000 Floor and wall covering work
Additional classification ( cpv ): 45440000 Painting and glazing work
Additional classification ( cpv ): 45450000 Other building completion work
Additional classification ( cpv ): 45100000 Site preparation work
Additional classification ( cpv ): 45110000 Building demolition and wrecking work and earthmoving work
Additional classification ( cpv ): 45200000 Works for complete or part construction and civil engineering work
Additional classification ( cpv ): 45210000 Building construction work
Additional classification ( cpv ): 45220000 Engineering works and construction works
Additional classification ( cpv ): 45260000 Roof works and other special trade construction works
Additional classification ( cpv ): 45300000 Building installation work
Additional classification ( cpv ): 45310000 Electrical installation work
Additional classification ( cpv ): 45320000 Insulation work

2.1.2 Place of performance

Country subdivision (NUTS) : Dublin ( IE061 )
Country : Ireland

2.1.3 Value

Maximum value of the framework agreement : 15 000 000 Euro

2.1.4 General information

Legal basis :
Directive 2014/24/EU

5. Lot

5.1 Lot technical ID : LOT-0001

Title : Multi-Party Framework Agreement for Minor Works on foot of an initial contract for remedial works to various unoccupied buildings across the Digital Hub Development Agency campus
Description : The Digital Hub Development Agency (DHDA), the Contracting Authority, is seeking to establish a Multi-Party Framework Agreement for Minor Works for suitably qualified and experienced Building Contractors on foot of an initial contract for remedial works to various unoccupied buildings across the Digital Hub Development Agency campus. The works that are subject to the competition will involve interaction with protected and listed structures, with all proposed works requiring adherence to preservation best practices. A summary of the works is listed below, please note this a non-exhaustive list: - Installation of external supporting steelworks and remediation of existing supporting steelworks, including installation of internal propping elements. - Timber works include stair restoration/construction, timber floor strengthening and replacement, roof repairs. - Roof repair works including, restoration and new construction. - External facade works include render crack repair, brickwork pointing and cladding installation. - Underpinning to existing historic foundation. There are various other projects which are envisaged under the Framework Agreement, please refer to enclosed documents for further particulars and general description of the works. Note that works are predominantly carried out to unoccupied buildings but there will be a certain amount of works which will take place in occupied buildings.
Internal identifier : 0

5.1.1 Purpose

Main nature of the contract : Works
Main classification ( cpv ): 45000000 Construction work
Additional classification ( cpv ): 45330000 Plumbing and sanitary works
Additional classification ( cpv ): 45340000 Fencing, railing and safety equipment installation work
Additional classification ( cpv ): 45350000 Mechanical installations
Additional classification ( cpv ): 45400000 Building completion work
Additional classification ( cpv ): 45410000 Plastering work
Additional classification ( cpv ): 45420000 Joinery and carpentry installation work
Additional classification ( cpv ): 45430000 Floor and wall covering work
Additional classification ( cpv ): 45440000 Painting and glazing work
Additional classification ( cpv ): 45450000 Other building completion work
Additional classification ( cpv ): 45100000 Site preparation work
Additional classification ( cpv ): 45110000 Building demolition and wrecking work and earthmoving work
Additional classification ( cpv ): 45200000 Works for complete or part construction and civil engineering work
Additional classification ( cpv ): 45210000 Building construction work
Additional classification ( cpv ): 45220000 Engineering works and construction works
Additional classification ( cpv ): 45260000 Roof works and other special trade construction works
Additional classification ( cpv ): 45300000 Building installation work
Additional classification ( cpv ): 45310000 Electrical installation work
Additional classification ( cpv ): 45320000 Insulation work

5.1.2 Place of performance

Town : dublin
Country subdivision (NUTS) : Dublin ( IE061 )
Country : Ireland
Additional information :

5.1.5 Value

Estimated value excluding VAT : 15 000 000 Euro

5.1.6 General information

Procurement Project not financed with EU Funds.
The procurement is covered by the Government Procurement Agreement (GPA) : yes

5.1.7 Strategic procurement

Aim of strategic procurement : Fulfilment of social objectives
Description : preserving and restoring derelict buildings
Approach to reducing environmental impacts : The transition to a circular economy
Social objective promoted : Other

5.1.8 Accessibility criteria

Accessibility criteria for persons with disabilities are not included because the procurement is not intended for use by natural persons

5.1.10 Award criteria

Criterion :
Type : Cost
Description : comparative cost for evaluation
Category of award threshold criterion : Weight (percentage, exact)
Award criterion number : 60
Criterion :
Type : Quality
Description : programme, methodology, reference projects
Category of award threshold criterion : Weight (percentage, exact)
Award criterion number : 40

5.1.12 Terms of procurement

Information about review deadlines : standstill period expired prior to forming the framework

5.1.15 Techniques

Framework agreement :
Framework agreement, with reopening of competition
Information about the dynamic purchasing system :
No dynamic purchase system

5.1.16 Further information, mediation and review

Review organisation : The High Court of Ireland
Information about review deadlines : standstill period expired prior to forming the framework
Organisation providing offline access to the procurement documents : The Digital Hub Development Agency

6. Results

Maximum value of the framework agreements in this notice : 15 000 000 Euro

6.1 Result lot ldentifier : LOT-0001

At least one winner was chosen.
Framework agreement :
Maximum value of the framework agreement : 15 000 000 Euro

6.1.2 Information about winners

Winner :
Official name : Glenlow Construction Ltd. T/A Nolan Construction
Tender :
Tender identifier : 000087791
Identifier of lot or group of lots : LOT-0001
Subcontracting : No
Contract information :
Identifier of the contract : 421971
Date on which the winner was chosen : 29/05/2025
Date of the conclusion of the contract : 13/06/2025

6.1.4 Statistical information

Received tenders or requests to participate :
Type of received submissions : Tenders
Number of tenders or requests to participate received : 6

8. Organisations

8.1 ORG-0001

Official name : The Digital Hub Development Agency
Registration number : DHDA Act 2003
Town : Dublin
Postcode : D08 PX8H
Country subdivision (NUTS) : Dublin ( IE061 )
Country : Ireland
Contact point : Sebastian Mansfield-Steer
Telephone : 01 480 6200
Roles of this organisation :
Buyer
Organisation providing offline access to the procurement documents

8.1 ORG-0002

Official name : Glenlow Construction Ltd. T/A Nolan Construction
Registration number : 521257
Postal address : Fairgreen, Hacketstown,
Town : Hacketstown
Postcode : R93RD37
Country subdivision (NUTS) : Dublin ( IE061 )
Country : Ireland
Telephone : 0876195784
Roles of this organisation :
Tenderer
Winner of these lots : LOT-0001

8.1 ORG-0003

Official name : The High Court of Ireland
Registration number : The High Court of Ireland
Department : The High Court of Ireland
Postal address : Four Courts, Inns Quay, Dublin 7
Town : Dublin
Postcode : D07 WDX8
Country subdivision (NUTS) : Dublin ( IE061 )
Country : Ireland
Telephone : +353 1 8886000
Roles of this organisation :
Review organisation

8.1 ORG-0004

Official name : European Dynamics S.A.
Registration number : 002024901000
Department : European Dynamics S.A.
Town : Athens
Postcode : 15125
Country subdivision (NUTS) : Βόρειος Τομέας Αθηνών ( EL301 )
Country : Greece
Telephone : +30 2108094500
Roles of this organisation :
TED eSender

11. Notice information

11.1 Notice information

Notice identifier/version : 9051debc-febb-416f-9fea-d613870ed68b - 01
Form type : Result
Notice type : Contract or concession award notice – standard regime
Notice dispatch date : 11/07/2025 17:37 +01:00
Languages in which this notice is officially available : English

11.2 Publication information

Notice publication number : 00460123-2025
OJ S issue number : 133/2025
Publication date : 15/07/2025